The 2nd Edition has (compare to 15 in 1999). Below is the simplified structure:
| Clause | Title | What It Covers | | :--- | :--- | :--- | | 1 | Definitions | Contract documents, Employer, Contractor, Subcontractor, Day, etc. | | 2 | Contract Documents | Priority of documents (Agreement → Special Conditions → Green Book clauses → Drawings) | | 3 | Employer’s Obligations | Provide site access, permits, and pay on time. | | 4 | Contractor’s Obligations | Execute works, provide supervision, comply with laws. | | 5 | Subcontracting | No subcontracting without consent. Contractor remains liable. | | 6 | Works by Employer | Employer may do separate work—coordination clause. | | 7 | Contractor’s Documents | Submittals (schedules, method statements). | | 8 | Commencement & Completion | Time for completion, possession of site. | | 9 | Variations | Changes to scope—must be in writing. | | 10 | Payment | Application for payment, due dates, interest on late payment. | | 11 | Retention | Usually 5% retention, released 50% at completion, 50% after defects period. | | 12 | Delay Damages | Liquidated damages for late completion (cap often 10% of contract price). | | 13 | Completion & Taking Over | Certificate of completion, transfer of risk. | | 14 | Defects Liability | Usually 12 months to fix defects. | | 15 | Suspension | Contractor can suspend if non-payment. | | 16 | Termination | Either party can terminate for material breach. | | 17 | Risk & Indemnity | Who bears loss/damage to works. | | 18 | Insurance | Required: liability, works, contractor’s equipment. | | 19 | Exceptional Events | Force majeure, pandemic, war—extends time, no damages. | | 20 | Claims & Disputes | Notice of claim within 28 days. | | 21 | Dispute Resolution | Adjudication (fast, binding temporarily) then arbitration. |
According to FIDIC's official documentation, the Green Book 2nd Edition continues the organization's "key principles of balanced risk sharing while seeking to build on the substantial experience gained from the original Green Book's use over the past 22 years". The updated contract is intended for projects "where the perceived level of risk is low, and/or where construction parties wish to use a form which is simple to use and does not require significant contract administration and management resources". It serves as a more accessible alternative to the more complex 2017 Red and Yellow Books, which are designed for larger, higher-risk projects.
The Short Form of Contract 2nd Ed - 2021 Green Book - PDF has 21 clauses, which are organized into the following main sections: short form of contract 2nd ed -2021 green book- pdf
It strengthens procedures regarding the Defects Notification Period and Taking-Over processes, while emphasizing dispute avoidance before it reaches formal adjudication.
The Short Form of Contract, also known as the Green Book, is a widely used contract document published by the International Federation of Consulting Engineers (FIDIC). The 2nd edition of the Green Book, released in 2021, provides a concise and practical contract for construction projects. In this article, we will explore the key features, benefits, and applications of the Short Form of Contract 2nd Ed - 2021 Green Book - PDF.
Final disputes are settled via ICC Expedited Procedure arbitration, typically with a sole arbitrator. 📂 Document Structure The contract follows a specific hierarchy of priority: Contract Agreement The 2nd Edition has (compare to 15 in 1999)
"Have you seen this?" he asked.
Unofficial PDFs often contain scanning errors, missing pages, or outdated text variants that can jeopardize the enforceability of your contract. How to Legally Access the Contract
The , commonly known as the Green Book , is structured into 14 clauses within its General Conditions. It is designed for projects with a low risk profile where parties prefer a simple contract that does not require extensive management resources. Contract Structure | | 4 | Contractor’s Obligations | Execute
Unlike its predecessor, the 2021 Green Book does not restrict usage based on a specific financial ceiling. It can be deployed for civil, mechanical, electrical, or building projects where the design is provided by either the Employer or the Contractor. 2. Introduction of the "Engineer"
Successfully executing a project under the 2021 Green Book requires strict adherence to its notice provisions and administrative timelines. Notices and Time Bars
This public link is valid for 7 days and shares a thread, including any personal information you added. This link or copies made by others cannot be deleted. If you share with third parties, their policies apply. Can’t copy the link right now. Try again later.
Before you download that PDF and fill in the blanks, ask yourself: